jagomart
digital resources
picture1_Sample Contract For Construction 83771 | Aia Errata


 275x       Filetype PDF       File size 0.16 MB       Source: goldcoastschools.com


File: Sample Contract For Construction 83771 | Aia Errata
aia errata for tabs aia a201 a201 aia document 201 2007 aia document 201 2017 ownership and use of drawings specifications and aia201 1 5 1 aia201 1 5 other ...

icon picture PDF Filetype PDF | Posted on 13 Sep 2022 | 3 years ago
Partial capture of text on file.
                                                       AIA ERRATA FOR TABS                     
         AIA A201: 
                                                                    A201 
                                                                       AIA Document 201 (2007)          AIA Document 201 (2017) 
          Ownership and Use of Drawings, Specifications and                  AIA201 (1.5.1)                    AIA201 (1.5) 
          Other Instruments of Service 
          Information and Services Required of the Owner                      AIA201 (2.3)                     AIA201 (2.2.1) 
          Except for permits and fees that are the responsibility            AIA201 (2.3.1)                    AIA201 (2.2.2) 
          of the Contractor under the Contract 
          Documents…(through) the Owner shall secure and 
          pay for necessary approvals, easements, 
          assessments and charges required for construction…  
          Unless otherwise provided in the Contract Documents,               AIA201 (2.2.5)                    AIA201 (2.3.6) 
          the Owner shall furnish to the Contractor one copy of 
          the Contract Documents for purposes of making 
          reproductions.  
          Owner’s Right to Carry out the Work: If the                         AIA201 (2.4)                     AIA201 (2.5) 
          Contractor defaults or neglects to carry out the Work in 
          accordance with the Contract …(through) the Owner 
          may have, correct such default or neglect.  
          The Work shall be in accordance with approved                      AIA201 (3.12.8)                  AIA201 (3.12.7) 
          submittals except that the Contractor shall not be 
          relieved …(through) (1)  
          If the Contractor does not respond promptly or                     AIA201 (7.3.7)                    AIA201 (7.3.4) 
          disagrees with the method for adjustment in the 
          Contract Sum, the Architect shall determine the 
          adjustment …(through) Highlight items 1 thru 5 and 
          pay special notice to sub article 3 “exclusive of hand 
          tools”.  
          If the Architect withholds certification for payment               AIA201 (9.5.3)                    AIA201 (9.5.4) 
          under Section 9.5.1.3, the Owner may…(through) 
          Contractor failed to make payment for Work properly 
          performed.  
          Failure to Purchase Required Property Insurance:                  AIA201 (11.3.1.2)                 AIA201 (11.2.2) 
          If the Owner fails to purchase and maintain the 
          required property insurance…(through) charged to the 
          Owner by a Change Order.  
          The Owner and Contractor waive all rights against (1) -            AIA201 (11.3.7)                  AIA201 (11.3.1) 
          (3) This waiver of subrogation shall be effective as to a 
          person or entity – highlight items (1) and (2) in the 
          same paragraph  
          A loss insured under the property insurance required               AIA201 (11.3.8)                  AIA201 (11.5.1) 
          by the Agreement shall be adjusted by the Owner as 
          fiduciary and made payable to the Owner as fiduciary 
          for the insureds, as their interests may appear.  
          Tests, inspections and approvals of portions of the                AIA201 (13.5.1)                  AIA201 (13.4.1) 
          Work shall be made as required by the Contract 
          Documents… (through) shall directly arrange and pay 
          for tests, inspections, or approvals where building 
          codes or applicable laws or regulations so require.  
                                           
                                                                 A201 (cont’d.) 
                                                                          AIA Document 201 (2007)            AIA Document 201 (2017) 
          Interest: Payments due and unpaid under the contract                   AIA201 (13.6)                     AIA201 (13.5) 
          Documents shall bear interest from the date payment 
          is due at the rate as the parties agree upon in writing 
          or, in the absence thereof, at the legal rate prevailing 
          from time to time at the place where the Project is 
          located.  
          Claims by either party shall be initiated within 21 days              AIA201 (15.1.2)                   AIA201 (15.1.3.1) 
          after occurrence of the event giving rise to such Claim 
          or within 21 days after the claimant first recognizes the 
          condition giving rise to the claim, whichever is later  
          If the Contractor wishes to make a Claim for an                      AIA201 (15.1.5.1)                  AIA201 (15.1.6.1)  
          increase in the Contract Time, notice as provided in 
          Section 15.1.3… (through) continuing delay, only one 
          Claim is necessary.  
          Waiver of Claims for Consequential Damages: The                       AIA201 (15.1.6)                    AIA201 (15.1.7)  
          Contractor and Owner waive Claim against each other 
          for consequential damages… This mutual waiver 
          includes: highlight items (1) - (2).  
         AIA A401: 
                                                                       A401 
                                                                          AIA Document 401 (2007)            AIA Document 401 (2017) 
          The Subcontract may be amended or modified only by                     AIA401 (1.4)                       AIA401 (1.3) 
          a Modification to this Subcontract.  
          The Contractor shall permit the Subcontractor to                      AIA401 (3.2.3)                     AIA401 (3.1.2)  
          request directly from the Architect information 
          regarding the percentages of completion and the 
          amount certified on account of Work done by the 
          Subcontractor.  
          If hazardous materials or substances are being used                   AIA401 (3.2.4)                       AIA (3.3.4) 
          on the site by the Contractor, a subcontractor, 
          …(through) sufficient detail and time to permit the 
          Subcontractor’s compliance with such laws.  
          The Contractor shall furnish to the Subcontractor                     AIA401 (3.2.5)                     AIA401 (3.3.5) 
          within 30 days after receipt of a written request, 
          …(through) enforce mechanic’s lien rights.  
          The Contractor’s Claims for the costs of services or                  AIA401 (3.3.2)                     AIA401 (3.4.2) 
          materials provided due to the Subcontractor’s failure to 
          execute the Work shall require: highlight items (1) – 
          (2).  
          Contractor’s Remedies: If the Subcontractor defaults                   AIA401 (3.4)                       AIA401 (3.5) 
          or neglects to carry out the Work in accordance with 
          this Agreement and fails… (through) the reasonable 
          cost from current or future payments due the 
          Subcontractor.  
          For all Work the Subcontractor intends to subcontract,                AIA401 (4.1.1)                     AIA401 (4.2.1) 
          the Subcontractor shall enter into written 
          agreements… (through) toward each other and having 
          the benefit of all rights, remedies and redress each 
          against the other that the Contractor and 
          Subcontractor have.  
          The Subcontractor shall supervise and direct the                      AIA401 (4.1.2)                     AIA401 (4.2.2) 
          Subcontractor’s Work, and shall cooperate with the 
          Contractor in scheduling and performing the 
          Subcontractor’s Work to avoid conflict, delay un, or 
          interference with the Work of the Subcontractor.  
                                                     A401 (cont’d.) 
                                                             AIA Document 401 (2007)     AIA Document 401 (2017) 
         The Subcontractor shall promptly submit Shop             AIA401 (4.1.3)              AIA401 (4.2.3.1) 
         Drawings, Product Data, Samples and similar 
         submittals required by the Subcontract Documents 
         with reasonable promptness and such sequence as to 
         cause no delay in the Work  
         The Subcontractor shall furnish to the Contractor        AIA401 (4.1.4)               AIA401 (4.2.4) 
         periodic progress reports on the Work of this 
         Subcontract…  
         The Subcontractor agrees that the Contractor and the     AIA401 (4.1.5)               AIA401 (4.2.5) 
         Architect each have the authority to reject Work of the 
         Subcontractor that does not conform to the Prime 
         Contract.  
         The Subcontractor shall take reasonable safety           AIA401 (4.3.1)               AIA401 (4.4.1) 
         precautions with respect to performance of this 
         Subcontract. The Subcontractor shall notify the 
         Contractor within three days an injury to an employee 
         or agent of the Subcontractor which occurred at the 
         site  
         The Subcontractor shall keep the premises and            AIA401 (4.4.1)               AIA401 (4.5.1) 
         surrounding area free from accumulation of waste 
         materials or rubbish caused by operations performed 
         under this Subcontract.  
         The Subcontractor warrants to the Owner, Architect,      AIA401 (4.5.1)               AIA401 (4.6.1) 
         will be free from defects, except for those inherent in 
         the quality of the Work the Subcontracts Documents 
         require or permit.  
         Remedies for Nonpayment: If the Contractor does not       AIA401 (4.7)                 AIA401 (4.8)  
         pay the Subcontractor through no fault of the 
         Subcontractor, within seven days … (through) Work of 
         this Subcontract until payment of the amount owing 
         has been received.  
         The period covered by each application for payment        AIA401 (11.2)              AIA401 (11.1.2) 
         shall be one calendar month ending on the last day of 
         the month.  
         Substantial Completion: Within 30 days following          AIA401 (11.9)               AIA401 (11.2) 
         issuance by the Architect of the certificate for payment 
         covering… (through) certificate to cover costs of items 
         to be completed or corrected by the Subcontractor.  
         Final payment, constituting the entire unpaid balance     AIA401 (12.1)              AIA401 (11.3.1) 
         of the Subcontract Sum, shall be made by the 
         Contractor… (through) the Owner, final payment to the 
         Subcontractor shall be made upon demand.  
         If the required property insurance is not in effect…     AIA401 (13.8.2)             AIA401 (12.4.2) 
         (through) insurance by an adjustment in the 
         Subcontract Sum.  
         
The words contained in this file might help you see if this file matches what you are looking for:

...Aia errata for tabs a document ownership and use of drawings specifications other instruments service information services required the owner except permits fees that are responsibility contractor under contract documents through shall secure pay necessary approvals easements assessments charges construction unless otherwise provided in furnish to one copy purposes making reproductions s right carry out work if defaults or neglects accordance with may have correct such default neglect be approved submittals not relieved does respond promptly disagrees method adjustment sum architect determine highlight items thru special notice sub article exclusive hand tools withholds certification payment section failed make properly performed failure purchase property insurance fails maintain charged by change order waive all rights against this waiver subrogation effective as person entity same paragraph loss insured agreement adjusted fiduciary made payable insureds their interests appear tests i...

no reviews yet
Please Login to review.